VIEWS: 463 PAGES: 5 CATEGORY: Business Services POSTED ON: 7/23/2011
This Electrician Services Agreement is made between an electrician and a client for the electrician's services. This document contains the material terms of the agreement including the services to be provided, the completion date and the payment details. It includes standard provisions that are commonly found in these types of agreements, and may be customized to address the specific needs of the parties. This agreement is useful to electricians and clients when engaging an electrician's services.
This Electrician Services Agreement is made between an electrician and a client for the electrician's services. This document contains the material terms of the agreement including the services to be provided, the completion date and the payment details. It includes standard provisions that are commonly found in these types of agreements, and may be customized to address the specific needs of the parties. This agreement is useful to electricians and clients when engaging an electrician's services. © Copyright 2012 Docstoc Inc. registered document proprietary, copy not 1 Electrician Services Agreement Agreement made on the (date), between (Name of Owner) of (street address, city, state, zip code), referred to herein as Owner, and (Name of Contractor), a corporation organized and existing under the laws of the state of (name of state), with its principal office located at (street address, city, state, zip code), referred to herein as Contractor. For and in consideration of the mutual covenants contained in this Agreement, and other good and valuable consideration, the parties agree as follows: I. Description of Work A. Contractor will perform all wiring work in the in the Owner’s Building located at (street address, city, state, zip code), in accordance with the Plans attached hereto as Exhibit A and made a part hereof. B. Wiring will be for overhead service unless otherwise stipulated, and Contractor will not be required to install underground service even though underground service may be necessary for the installation of a complete electrical system, unless Contractor has included the same in this Agreement and has so designated it in the above schedule. C. Feeder circuits to garage or outbuildings will be run overhead unless otherwise stipulated in this Agreement. II. Contract Time The work shall be completed within (number) calendar days from (date). III. Contract Price. Owner will make payments on account of the contract price as follows: A. On or about the (number) day of each week during construction, a payment equivalent to ____% of the value of the work completed. B. When roughing-in is completed and has passed inspection (if subject to inspection) and the balance when the job is completed and has passed final inspection, an amount equivalent to ______% of the contract price. C. On final completion of the work and settlement of all claims, the remainder of the contract price. IV. Fixtures This contract is for wiring only and does not include fixtures, or an allowance for fixtures or other equipment, unless so stipulated. Fixtures, as used in this Section, means personal property that is attached to the earth or placed in a building in such a way or under such circumstances that it is deemed to be part of the real property. © Copyright 2012 Docstoc Inc. registered document proprietary, copy not 2 V. Overtime Work Overtime work is not contemplated and shall not be required as a part of this contract. If it is necessary for Contractor to work overtime, the expense for such overtime work shall be paid to Contractor, plus overhead and profit, and shall be agreed on before Contractor is required to proceed. VI. Roughing-In Contractor shall not be obliged under any circumstances to alter the roughing-in after plastering has commenced. Owner agrees not to permit lathing and plastering to be commenced until the roughing-in payment required by this contract shall have been made to Contractor. VII. Severability. The invalidity of any portion of this Agreement will not and shall not be deemed to affect the validity of any other provision. If any provision of this Agreement is held to be invalid, the parties agree that the remaining provisions shall be deemed to be in full force and effect as if they had been executed by both parties subsequent to the expungement of the invalid provision. VIII. No Waiver. The failure of either party to this Agreement to insist upon the performance of any of the terms and conditions of this Agreement, or the waiver of any breach of any of the terms and conditions of this Agreement, shall not be construed as subsequently waiving any such terms and conditions, but the same shall continue and remain in full force and effect as if no such forbearance or waiver had occurred. IX. Governing Law. This Agreement shall be governed by, construed, and enforced in accordance with the laws of the State of (name of state). X. Notices. Unless provided herein to the contrary, any notice provided for or concerning this Agreement shall be in writing and shall be deemed sufficiently given when sent by certified or registered mail if sent to the respective address of each party as set forth at the beginning of this Agreement. XI. Mandatory Arbitration. Notwithstanding the foregoing, and anything herein to the contrary, any dispute under this Agreement shall be required to be resolved by binding arbitration of the parties hereto. If the parties cannot agree on an arbitrator, each party shall select one arbitrator and both arbitrators shall then select a third. The third arbitrator so selected shall arbitrate said dispute. The arbitration shall be governed by the rules of the American Arbitration Association then in force and effect. XII. Entire Agreement. This Agreement shall constitute the entire agreement between the parties and any prior understanding or representation of any kind preceding the date of this Agreement shall not be binding upon either party except to the extent incorporated in this Agreement. XIII. Modification of Agreement. Any modification of this Agreement or additional obligation assumed by either party in connection with this Agreement shall be binding © Copyright 2012 Docstoc Inc. registered document proprietary, copy not 3 only if placed in writing and signed by each party or an authorized representative of each party. XIV. Assignment of Rights. The rights of each party under this Agreement are personal to that party and may not be assigned or transferred to any other person, firm, corporation, or other entity without the prior, express, and written consent of the other party. XV. Counterparts. This Agreement may be executed in any number of counterparts, each of which shall be deemed to be an original, but all of which together shall constitute but one and the same instrument. XVI. Compliance with Laws. In performing under this Agreement, all applicable governmental laws, regulations, orders, and other rules of duly-constituted authority will be followed and complied with in all respects by both parties. WITNESS our signatures as of the day and date first above stated. (Name of Contractor) ________________________ By: ________________________________ (Printed Name of Owner) (Printed name & Office in Corporation) (Signature of Owner) (Signature of Officer) © Copyright 2012 Docstoc Inc. registered document proprietary, copy not 4
Pages to are hidden for
"Electrician Services Agreement"Please download to view full document