Adjudication Contract by uui18871

VIEWS: 0 PAGES: 2

More Info
									                   Application for Nomination of an Adjudicator by AICA

Applicant (Referring) Party
Address




Tel No.                                                              Fax No.
E-mail
Applicant Representative
Address




Tel No.                                                              Fax No.
E-mail


Other (Responding) Party
Address




Tel No.                                                              Fax No.
E-mail
Other Party Representative
Address




Tel No.                                                              Fax No.
E-mail



Is this application made in accordance with adjudication provisions in the contract?                Yes / No

Is this application made in accordance with the Scheme for Construction Contracts?                  Yes / No

Does the contract identify a particular Adjudicator Nominating Body? Please specify

Is this application made under a Scottish or Scottish version of a contract?                        Yes / No

Are you a member of a Trade Association? Please specify


                                                            AICA
                                Royal London House, 22-25 Finsbury Square, London, EC2A 1DX
                           T: 0844 249 5353 F: 0844 249 5354 E: enquiries@aica-adjudication.co.uk
                                                 www.aica-adjudication.co.uk
                        CONTRACT                                            DISPUTE
 Construction
  Main Contract                                         Certification and Valuation
  Main Contract (Design & Build)                        Contractual/Legal Interpretation
  Sub Contract                                          Defective Workmanship
  Sub Contract (Design & Build)                         Delay, EOT and Liquidated Damages
  Sub Sub Contract                                      Design
  Sub Sub Contract (Design & Build)                     Determination
  Other – please specify                                Insurance
                                                        Loss and Expense
 Professional Services                                  Workmanship
  Architectural    Building                             Payment
                   Landscaping                          Warranties and Bonds
  Surveying        Building                             Set-Off
                   Quantity                             Suspension of Works
  Engineering      Geo-technical                        Variation
                   M&E                                  Other – please specify
                   Structural
  Civil Engineer
  Sub-Consultancy
  Other – please specify



 Qualifications/
 specialisms of adjudicator
 considered appropriate



 Names of any adjudicators
 you consider unacceptable
 with reasons supporting
 your views




 Date of Notice of
 Adjudication


Following nomination by the Association of Independent Construction Adjudicators (AICA), we undertake to be
responsible for payment of the reasonable fees and expenses of the Adjudicator including where a negotiated
settlement is reached before the Adjudicator makes a decision.

 Signed                                                Dated



 Checklist:                                            Return to:

       Completed application form                      AICA
                                                       Royal London House
       Administration fee of £300                      22-25 Finsbury Square
       (Cheque made payable to Association of          London
       Independent Construction Adjudicators)          EC2A 1DX
       Notice of Adjudication                          T: 0844 249 5353
                                                       F: 0844 249 5354
       Copy of contract adjudication provisions        E: enquiries@aica-adjudication.co.uk
                                                       www.aica-adjudication.co.uk

								
To top