VIEWS: 1,504 PAGES: 8 CATEGORY: Buying and Selling Commercial Real Estate POSTED ON: 12/1/2009
This Remodeling Agreement is a contract between the owner of commercial property and a contractor for the remodeling of the commercial property. This agreement includes the terms and conditions for the contractor's duties, payments, description of the work to be completed, completion dates, and material and labor costs. The form contains both standard clauses and opportunities for the use of optional terms and conditions making it fully customizable to fit the needs of the contracting parties. This document is ideal for commercial property owners to organize and clarify a remodeling agreement with a contractor.
This Remodeling Agreement is a contract between the owner of commercial property and a contractor for the remodeling of the commercial property. This agreement includes the terms and conditions for the contractor's duties, payments, description of the work to be completed, completion dates, and material and labor costs. The form contains both standard clauses and opportunities for the use of optional terms and conditions making it fully customizable to fit the needs of the contracting parties. This document is ideal for commercial property owners to organize and clarify a remodeling agreement with a contractor. COMMERCIAL BUILDING REMODELING AGREEMENT This Commercial Building Remodeling Agreement (this “Agreement”) is hereby made and entered into this ____ day of _____________, 2______ by and between ____________________ (“Client”) and __________________ (“Contractor”) collectively referred to herein as the “Parties”. WHEREAS, Contractor provides contracting services (the “Services”) for the purposes of remodeling; and WHEREAS, Client wishes to obtain the Services of Contractor concerning the remodeling of Client’s commercial property in accordance with the Services outlined in Schedule “A” attached hereto (the “Project”); NOW, THEREFORE, in consideration of the foregoing and of the mutual promises and covenants contained herein, and other good and valuable consideration, the receipt of which is hereby acknowledged, the Parties hereto agree as follows: 1.00 SERVICES 1.01 Client and Contractor hereby agree that Contractor shall provide and perform the Services for Client at Client’s property located at ______________________ (the “Property”) for the purposes of completing the Project. 1.02 Client and Contractor hereby acknowledge and agree that the specific Services to be performed by Contractor for and on behalf of Client to complete the Project are contained in Schedule “A” annexed hereto. 1.03 Client hereby acknowledges and agrees that it shall obtain all necessary permits and approvals from any governmental authorities, including but not limited to, any zoning, building, or electrical permits, prior to Contractor commencing the Services. 1.04 Contractor hereby acknowledges and agrees that it shall contact and make the necessary arrangements with all appropriate authorities for inspections required for any Services completed in connection with the Project. Contractor shall post bond in accordance with the requirements of the municipal authority. 2.00 CONSIDERATION 2.01 Client hereby agrees that it shall pay to Contractor in respect of the Services provided by Contractor for completion of the Project, the amount of ________________________ dollars ($_______) (the “Consideration”) plus all applicable taxes and all costs incurred by Contractor for materials used in respect of the Project. © 2013 by Docstoc®, Inc. 2 2.02 Client hereby agrees that it shall pay to Contractor the Consideration by way of cash, check, or certified check, or by such other means as the Parties hereto may agree in writing. 2.03 Client shall pay the Consideration due and owing to Contractor plus all applicable taxes and amounts due and owing to Contractor for all costs incurred by Contractor in respect of materials used for the Project, upon satisfactory completion of the Project. 2.04 Client hereby acknowledges and agrees that interest shall be payable by Client at the rate of _________ percent (___%) per month on any and all amounts that remain unpaid to Contractor. 3.00 COMMENCEMENT AND COMPLETION DATE 3.01 Client and Contractor hereby acknowledge and agree that the Services to be performed by Contractor in respect of the Project shall commence on the _____ day of __________, 2________ or at such other date as the Parties hereto in writing may agree. 3.02 Client and Contractor hereby agree that the Completion Date (the “Completion Date”) for the Project shall be _____________________, or such other date as the Parties hereto in writing may agree. 4.00 INDEPENDENT CONTRACTOR 4.01 Client and Contractor hereby acknowledge and agree that Contractor shall perform all of the Services contemplated herein for the Project as an independent contractor and shall at all times or time, use its own tools and equipment for the Services to be performed. 4.02 Client hereby acknowledges and agrees that Contractor shall perform all of the Services contemplated herein independent of Client’s supervision, being only responsible for satisfactory completion of the Project. 4.03 Client hereby acknowledges and agrees that Contractor may at times use subcontractors for part of the Services to be performed, but shall be solely responsible for supervising the work of any subcontractors and for the quality of work such subcontractors produce. 5.00 COMPLIANCE BY CONTRACTOR 5.01 Contractor shall, at all times, be in compliance with all state and local licensing and registration requirements for the type of Services to be provided to Client and shall provide to Client copies of such licensing compliance prior to the commencement of the Services upon request. © 2013 by Docstoc®, Inc. 3 6.00 LIABILITY AND INSURANCE 6.01 Contractor shall maintain at all times a minimum standard commercial public liability and property damage insurance with a ____________________ dollar ($____________) coverage limit together with all other state-legislated worker’s compensation insurance coverage and any other insurance as may be reasonably required. 6.02 Contractor hereby agrees that it releases and forever discharges Client from any and all liability for any injuries incurred by Contractor, its employees, or its subcontractors while performing the Services for Client to the fullest extent allowed by law. 7.00 LIENS AND WAIVERS 7.01 Contractor hereby acknowledges and agrees that it shall provide to Client, upon completion of the Project, lien waivers, releases, or acknowledgements from each subcontractor or material provider, acknowledging that such subcontractor or material provider has been paid in full. 7.02 Contractor hereby agrees that it shall not use any materials from any supplier without obtaining an acknowledgment of full payment for the materials. 8.00 MATERIALS 8.01 Any and all material used by Contractor in connection with the Services shall be new, in compliance with all applicable laws and codes, and be covered by a manufacturer’s warranty, if applicable. 9.00 REPRESENTATIONS AND WARRANTIES 9.01 Contractor hereby represents and warrants to Client as follows: (i) Contractor shall complete all Services in a workmanlike manner according to standard practices prevalent in Contractor’s trade; (ii) All Services completed shall comply with all applicable building codes and regulations; and (iii) The materials used for the Services shall be free and clear from defects. 10.00 DISPUTE RESOLUTION 10.01 Client and Contractor hereby acknowledge and agree that should any © 2013 by Docstoc®, Inc. 4 dispute arise under the terms of this Agreement, the Parties hereto agree to appoint a mutually-agreeable third party to mediate such dispute. 10.02 Should any such mediation be deemed unsuccessful, the dispute shall be decided by a court of applicable jurisdiction. The decision of the judge shall be final and binding on the Parties. 10.03 Any fees or costs incurred associated with any such mediation shall be shared equally by the Parties. 10.04 Any attorney fees incurred by the prevailing Party shall be paid by the other Party. 11.00 INDEMNIFICATION 11.01 Contractor hereby agrees that it shall hold harmless and indemnify Client for all damages, costs, and attorney fees that may arise out of harm caused to Contractor, subcontractors, or any other third party, known or unknown, by Contractor’s performance of the Services. 12.00 GENERAL 12.01 This Agreement shall be governed by and interpreted according to the laws of the State of _____________________________. 12.02 Contractor’s liability, under this Agreement and any other contract entered into pursuant to the terms hereof, shall be strictly limited to the value of the Services agreed to be performed. 12.03 This Agreement may not be assigned or transferred by Contractor without the express written consent of Client, which consent may be withheld in Client’s discretion. 12.04 This Agreement and the schedules referred to herein constitute the entire agreement between the Parties and supersede all prior agreements, representations, warranties, statements, promises, information, arrangements, and understandings, whether oral or written, express or implied, with respect to the subject matter hereof. The Parties further acknowledge and agree that, in entering into this Agreement, they have not in any way relied, and will not in any way rely upon, any oral or written agreements, representations, warranties, statements, promises, information, arrangements, or understandings, express or implied, not specifically set forth in this Agreement or in such schedules, documents, or instruments. 12.05 This Agreement shall be binding upon and inure to the benefit of the © 2013 by Docstoc®, Inc. 5 Parties and their respective heirs, administrators, executors, successors, and permitted assigns. Nothing herein, express or implied, is intended to confer upon any person, other than the Parties and their respective heirs, administrators, executors, successors, and permitted assigns, any rights, remedies, obligations, or liabilities under or by reason of this Agreement. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the date first above written. CONTRACTOR Per: Name: Title: I have authority to bind Contractor. Witness: Client © 2013 by Docstoc®, Inc. 6 SCHEDULE “A” SERVICES © 2013 by Docstoc®, Inc. 7
Pages to are hidden for
"Commercial Remodeling Agreement"Please download to view full document