Request for Qualifications

Document Sample
Request for Qualifications Powered By Docstoc
					                                     Executive Office
                                            for
                                  Administration & Finance




Request for Qualifications for TRADE CONTRACTORS
Construction Manager at Risk – M.G.L. c.149A, §8
For the Following Trades: (Insert Trades)
Massachusetts State Project (Insert Project Number)
                       (Insert Full Project Name, Town, Massachusetts)

Submission Deadline:                                            (Date) at 12:00 PM

Submit Statement of Qualifications to:                          DCAM Bid Room
                                                                Division of Capital Asset Management
                                                                One Ashburton Place, 16th Floor
                                                                Boston, MA 02108
(Date Issued)



DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number
               Part One: Request for Qualifications to Trade Contractors

Section I:         General Information
Section II:        Detailed Project Description
Section III:       General Instructions
Section IV:        Overview Of Prequalification Process
Section V:         Administration/Schedule For Prequalification Process
Section VI:        Evaluation Procedure/Criteria For Prequalification Selection
Section VII: Additional Information


          Part Two: Trade Contractor SOQ Application Forms/Schedules
                                       (to be completed by Trade Contractor)

Trade SOQ Form 1:                      RFQ Interest Form
Trade SOQ Form 2:                      RFQ Response Checklist
Trade SOQ Form 3:                      SOQ Application Form
Schedule A:                            Business Owner Information
Schedule B:                            Management Personnel Information
Schedule C:                            Similar Project Experience
Schedule D:                            Terminations
Schedule E:                            Legal Proceedings
Schedule F:                            Safety Record
Schedule G:                            Project References
Schedule H:                            Credit References
Schedule I:                            Public Project References
Schedule J:                            Prior Revenue
Schedule K:                            Revenue Under Contract
Schedule L:                            Bonding Letter




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number
Part One: Request for Qualifications to Trade Contractors

Section I: General Information

         A.        Introduction

        This Request for Qualifications (“RFQ”) is the first phase of a two-phase procurement
process as set forth in MGL Chapter 149A. DCAM through its Trade Contractor Prequalification
Committee is prequalifying firms interested in providing public Trade Contractor services on this
Public Construction Manager at Risk (“CM” or “CM at Risk”) project through this RFQ process.
DCAM will evaluate submitted Statements of Qualifications (“SOQs”) based upon the identified
evaluation criteria and points set forth in Section VI below and only those firms obtaining the
required minimum points will be deemed prequalified. Only those respondents deemed
prequalfied will be invited to submit a bid in response to a Request for Bids (“RFB”) which will
be issued in the second phase of the procurement process. The project delivery method for
construction will be public CM at Risk with a Guaranteed Maximum Price (“GMP”) under
M.G.L. Chapter 149A.

         B.        General Project Information

 Awarding Authority:                                            Division of Capital Asset Management
 Project No.:                                                   (Insert Project Number)
 Project Name:                                                  (Insert Project Name in Full)
 Project Location:                                              (Insert Project Location)
 Project Description:                                           (Insert Overall Project Description)
 RFQ Informational Meeting                                      (Insert Date and Time)
 (if applicable):                                               (Insert Location) if applicable; otherwise N/A
 Optional Site Visit                                            (Insert Date and Time)
 (if applicable):                                               (Insert Location) if applicable; otherwise N/A
 Submission Deadline:                                           (Insert Date)
 (for submission of SOQs in response to this RFQ)               12:00 pm (noon)
 Submission Address:                                            DCAM BID ROOM
                                                                Room 1610
                                                                One Ashburton Place, 16th Floor
                                                                Boston, MA 02108
                                                                (617) 727-4003
 Estimated Total Overall Project                                $ (Insert total amount for entire project)
 Construction Cost (does not include CM
 Fee/General Conditions):
 Estimated Total Project Duration:                              (Insert days/weeks from Notice to Proceed)
 CM at Risk Firm:                                               (Insert Firm Name)
 Project Architect:                                             (Insert Firm Name)

 DCAM Project Manager:                                          (Insert Name)


DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                2
         C.        Trade Contractors To Be Prequalified

         This RFQ seeks firms interested in providing Trade Contractor services on the Project in
the trades identified in the table below. Interested Trade Contractors in the categories identified
in the table below are invited to submit a Trade Contractor Statement of Qualifications (“SOQ”)
to DCAM. Trade Contractors in the various trades will be prequalified either on a trade by trade
basis, in phases, in groups of trades, or all at once depending on the project needs and phasing.

         Trade Contractors seeking prequalification for this project MUST submit a commitment
letter stating its ability to obtain bonding for 110% of the estimated trade contract value for the
particular Trade Contract from a surety company licensed to do business in the Commonwealth
or appearing on the U.S. Treasury Department Circulate 570. The selected Trade Contractors on
this CM at Risk project will then be required to provide payment and performance bonds for the
full value of their subcontracts and Trade Contractors must include the cost of these bonds in
their bids.

See “X” Below For                Section        Trade Category                            Estimated
ALL Trades Subject               #                                                        Construction
To Prequalification                                                                       Cost For Each
(at this time)                                                                            Trade
                                 040001         Masonry                                   (Insert $ amount or
                                                                                          N/A for each trade)
                                 050001         Miscellaneous and Ornamental Iron
                                 070001         Waterproofing, Dampproofing and
                                                Caulking
                                 070002         Roofing and Flashing
                                 080001         Metal Windows
                                 080002         Glass and Glazing
                                 090001         Lathing and Plastering
                                 090002         Tile
                                 090003         Acoustical Tile
                                 090004         Marble
                                 090005         Resilient Floors
                                 090006         Terrazzo
                                 090007         Painting
                                 140001         Elevators
                                 210001         Fire Protection Sprinkler System
                                 220001         Plumbing
                                 230001         Heating, Ventilation & Air-Conditioning
                                 260001         Electrical
                                 (Sec. #)       Other Designated Trade Categories
                                                (if any)




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                3
Section II: Detailed Project Description

(Detailed project description inserted here)

The project will be subject to the minimum wage rates set under the Massachusetts Prevailing
Wage Laws.

The project Minority Business Enterprise (“MBE”) participation goal is 7.4%
The project Women Business Enterprise (“WBE”) participation goal is 4.0%
Workforce utilization goals will apply to the project.

DCAM uses PMAS/PROLOG project management system for its projects and the selected Trade
Contractors may be required to utilize the system for project communication, tracking, etc.

Drawings, specifications, and other documents will not be available to respondents during the
RFQ phase.

Pursuant to M.G.L. c. 30, §39S(a)(2) all employees to be employed on the Project must have
successfully completed a course in construction safety and health approved by OSHA and of at
least 10 hours in duration. All Trade Contractors on the Project will also be required to provide
written certification of compliance with applicable workforce related laws, including, Executive
Order 481, Federal Department of Homeland Security Requirements, and laws relating to worker
classification, workers’ compensation, and applicable laws related to taxes and insurance.

Section III: General Instructions

In response to this RFQ, interested Trade Contractors are requested to submit a Trade Contractor
RFQ Interest Form (attached hereto) and required to submit a Statement of Qualifications
(“SOQ”) application package as follows:

         A.        Contents Of Statement Of Qualifications Application Package

                   The required SOQ application package consists of the following*:

                             1.        Trade Contractor Statement of Qualifications Form (Trade RFQ
                                       Form 3)
                             2.        Schedules A through M to Trade RFQ Form 3;
                             3.        all supporting documentation referenced and required therein; and
                             4.        required number of copies of items 1-3 above.

                   *Trade RFQ Form 2 “Trade Contractor RFQ Response Checklist” is also included
                   for the assistance of respondent Trade Contractors.

         B.        Submission Deadline: See Section I: General Information

                   An original, marked “Original” clipped, not stapled, together and five (5)
                   complete copies of the interested Trade Contractor’s SOQ application package
DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                4
                   must be received by DCAM on or before the Submission Copies should be stapled
                   together and submitted without any binders, dividers or report covers. Deadline as
                   set forth in Section I, as determined by DCAM’s date/time stamp. All envelopes
                   should be mailed or delivered to:

                                       DCAM Bid Room, Room 1610
                                       Division of Capital Asset Management
                                       One Ashburton Place, 16th Floor
                                       Boston, MA 02108
                                       Telephone: (617) 727-4003

                   SOQ application packages received by DCAM later than the Submission Deadline
                   specified in Section I will be rejected and returned to the respondent Trade
                   Contractor. Respondent Trade Contractors are cautioned to allow sufficient time
                   for mailed materials to be received. Telecopied, faxed, or e-mailed qualifications
                   will not be accepted. DCAM shall not be responsible for mail not received,
                   deliveries not made, or SOQ application packages not received by the date and
                   time set forth in Section I.

         C.        Required Exterior Label For SOQ Application Package Envelope

                   SOQs will not be read publicly and should be submitted in a sealed envelope. All
                   envelopes must be labeled on the outside with the following information:

                             “RFQ for Trade Contractor Services”
                             Project Name
                             Project Number
                             Trade for Which Submission is Made (i.e. masonry, electrical)
                             Respondent Trade Contractor’s Name
                             Respondent Trade Contractor’s Address
                             Respondent Trade Contractor’s Telephone Number
                             Respondent Trade Contractor’s Contact Person

         D.        RFQ Informational Meeting and/or Optional Site Visit (if applicable)

                   If indicated in Section I, an informational meeting regarding the prequalification
                   process for this Project will be held and/or a site visit will be available during the
                   RFQ Phase.

         E.        Review/Availability Of Contract Documents

                   Drawings, specifications and other documents will not be available to respondent
                   Trade Contractors during the RFQ Phase.

         F.        Additional Instructions


DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                5
                   See Section VII: Additional Information for additional instructions regarding the
                   prequalification process.


Section IV: Overview Of Prequalification Process

             This Request for Qualifications (“RFQ”) is issued pursuant to M.G.L. c. 149A, §8.
              Firms interested in providing Trade Contractor Services for the construction of the
              project described in Section I and Section II (“the Project”) MUST submit a Statement
              of Qualifications (“SOQ”) in response to this RFQ to DCAM as instructed in Section
              III and Section VIII, herein.

             The Trade Contractor selection process for this CM at Risk Project is a two-phase
              process as set forth in M.G.L. c. 149A, §8. The project delivery method for
              construction will be under M.G.L. c. 149A. DCAM is prequalifying firms interested
              in providing Trade Contractor services for the Project through this RFQ
              prequalification process.




          ******************** IMPORTANT NOTICES **********************

Participation in the RFB Bidding Phase of this Project will be limited to ONLY those Trade
Contractor firms who have submitted a SOQ (and required supporting documentation) in
response to this RFQ and that have been deemed prequalified by DCAM.

Trade Contractors that fail to respond to this RFQ and fail to submit an SOQ with the
required supporting documentation by the Submission Deadline set forth in Section I, and
Trade Contractors that have not been deemed prequalified by DCAM shall be
automatically disqualified from bidding on this Project.

          ******************** IMPORTANT NOTICES **********************




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                6
Section V: Administration/Schedule for Prequalification Process

         A.        “Two-Phase” Selection Process - Selection of Trade Contractors for the Project
                   will be conducted in a two-phase process as set forth in M.G.L. c. 149A, §8.
                   Trade Contractor firms must first be prequalified in the Phase One –
                   RFQ/Prequalification Phase in order to bid on the Project in Phase 2 –
                   RFB/Bidding Phase.

                   1.        Phase One – RFQ/Prequalification Phase

                                      Submission Of Statement Of Qualifications (“SOQ”) - Interested
                                       Trade Contractor firms must submit a completed SOQ; completed
                                       Schedules A through M, and all required supporting documentation
                                       referenced therein in response to this RFQ by the Submission
                                       Deadline set forth in Section I.

                                      Prequalification Committee –DCAM will appoint a
                                       Prequalification Committee to review and evaluate the SOQs (and
                                       supporting documentation) submitted by interested Trade
                                       Contractors. The Prequalification Committee shall consist of a
                                       representative from the Project Designer; a representative from the
                                       Construction Manager At Risk firm; and two (2) representatives
                                       appointed by DCAM.

                                      Evaluation By Prequalification Committee - The
                                       Prequalification Committee shall meet as necessary to evaluate and
                                       review the SOQs (and supporting documentation) submitted by
                                       each respondent Trade Contractor firm in accordance with the
                                       evaluation criteria set forth in Section VI.

                                      Notice To Respondent Trade Contractors – The names of the
                                       Trade Contractor firms responding to the RFQ will be posted in a
                                       Register of Responders but there will be no public opening of the
                                       SOQs submitted in response to the RFQ. Upon completion of the
                                       evaluation and review process described herein, the
                                       Prequalification Committee will provide written notice to all
                                       respondent Trade Contractors as to whether they are deemed
                                       prequalified or not. Prequalified Trade Contractor firms shall also
                                       be invited to participate in Phase Two, the RFB/Bidding Phase of
                                       the Trade Contractor selection process.




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                7
                   2.        Phase Two – RFB/Bidding Phase

                                      Trade Contractor firms determined in Phase One by the
                                       Prequalification Committee to be prequalified will be invited to
                                       bid on the Project. Only firms deemed prequalified during
                                       Phase One – RFQ/Prequalification Phase will be permitted to
                                       participate in Phase Two, the RFB/Bidding Phase. Firms that
                                       are not prequalified by the Prequalification Committee and firms
                                       that do not participate in the RFQ phase will be precluded from
                                       participating in Phase Two - the RFB Bidding/Phase.

         B.        Anticipated Schedule For Prequalification/Bidding

                 Anticipated Completion of Trade                    (Insert Date)
                 Prequalification Evaluations:
                 Anticipated RFB to Prequalified                    (Insert Date)
                 Bidders:
                 Anticipated Notice To Proceed:                     Varies Based on Trade
                 Anticipated Construction Schedule:                 Total Project Completion
                                                                    Anticipated (Insert Season,
                                                                    Year)


Section VI: Evaluation Procedure/Criteria For Prequalification Selection

         A.        Sources of Information Considered

                   Respondent Trade Contractors must submit documentation for the four (4)
                   statutory evaluation criteria categories listed herein. Prequalification will be
                   based on the submitted information and materials as well as information on prior
                   project performance, information obtained from references, information obtained
                   from governmental agencies and entities, information contained within DCAM’s
                   certification files, and such other information as may be obtained relating to the
                   evaluation criteria categories. The Prequalification Committee may also request
                   and review additional information as necessary to clarify or supplement the
                   information provided to or obtained by DCAM.

                   Do not include superfluous material. Respondent Trade Contractor must include
                   the Trade Contractor Statement of Qualifications Form, Trade RFQ Form 3 and
                   Schedules A through M attached hereto. Respondent Trade Contractor must give
                   complete and accurate answers to all questions and provide all of the information
                   requested. Making a materially false statement in this SOQ submission is grounds
                   for rejection and debarment.




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                8
         B.        Evaluation Procedure

                   As set forth herein and in accordance with M.G.L. c. 149A, §8, DCAM has
                   established a Prequalification Committee for the purpose of reviewing and
                   evaluating responses to this RFQ. The Prequalification Committee shall evaluate
                   interested Trade Contractors based on the evaluation criteria set forth herein and
                   assign points for each evaluation criterion category and subcategory provided
                   herein. The Prequalification Committee shall prepare a written evaluation score
                   form for each respondent Trade Contractor that provides a composite point rating
                   and a specific point rating for each of the evaluation criterion set forth in M.G.L.
                   c. 149A and herein. The Prequalification Committee shall only prequalify those
                   Trade Contractor firms that have achieved the minimum points required in each
                   category set forth herein and a minimum total score of seventy (70) points.

                   Only Trade Contractor firms achieving the minimum score required in each
                   evaluation category set forth herein, as well as a minimum total score of seventy
                   (70) points overall shall be prequalified and invited to submit bids consistent
                   with M.G.L. c. 149A, §8(a)-(f). An interested Trade Contractor’s score shall be
                   made available to the Trade Contractor upon request but is not a public record.

                   The decision of the Prequalification Committee shall be final and shall not be
                   subject to appeal except on grounds of fraud or collusion.

         C.        Criteria For Prequalification

                   SOQs must be submitted on the Trade RFQ Form 3 attached hereto. Interested
                   Trade Contractors submitting a SOQ and supporting information in any other form
                   will not be prequalified. The Prequalification Committee shall review and
                   evaluate the information submitted by interested Trade Contractors in accordance
                   with the statutory point scheme set forth in M.G.L. c. 149A, §8(e). Also in
                   accordance with §8(e), the RFQ shall set forth the available points for each
                   evaluation sub-category in order to provide interested Trade Contractors prior
                   notice of the points available in each sub-category. Joint ventures must provide
                   information about each of the joint venture partners.

                   1.        Management Experience - (50 points available in this category;
                             minimum of 25 points required in this category for prequalification
                             approval)

                             a.        Business Owners: Provide the name, title, including a detailed
                                       description of the role and job responsibilities, scope of work and
                                       numbers of years with the firm for each of the business owner(s) of
                                       the firm. If the respondent Trade Contractor is a partnership,
                                       respondent Trade Contractor MUST provide the requested
                                       information for each general and limited partner. If the respondent
                                       Trade Contractor is a corporation or limited liability company,
                                       respondent Trade Contractor MUST provide the requested
DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                9
                                       information for each officer, director and/or member. If the
                                       respondent Trade Contractor is a joint venture, respondent Trade
                                       Contractor must provide information about the nature of the joint
                                       venture including the approximate percentage participation by each
                                       joint venture partner and the division of responsibility among the
                                       joint venture partners. 1 point(s) available

                             b.        Management Personnel: Provide the name, title, including a
                                       detailed description of the role and job responsibilities, scope of
                                       work, education, construction experience, years with the firm and
                                       list of all projects completed for all management personnel who
                                       will have any direct or indirect responsibility over the Project,
                                       including but not limited to project executives, project managers,
                                       field superintendents and field engineers along with an
                                       organizational chart. Joint ventures must identify the company that
                                       employs each individual listed.       8 points available

                             c.        Similar Project Experience: Provide the project name(s) and
                                       location, owner, description, a detailed scope of work, original
                                       contract sum, final contract sum, with explanation, for that scope
                                       of work only and date of completion for each and every similar
                                       project undertaken by the firm in the last five (5) years. Joint
                                       ventures must provide similar project experience for each
                                       individual joint venture partner. For purposes of this RFQ,
                                       “similar projects” shall mean projects where: 1) the
                                       respondent was a Filed Sub bidder, Trade Contractor or
                                       subcontractor, preferably on a public building construction
                                       project in Massachusetts; 2) the respondent’s subcontract was
                                       for a similar dollar value as the work of its trade as stated in
                                       Section 1C of this RFQ; and 3) where the project was of
                                       similar size, scope and complexity as this Project. If specific
                                       criteria are required for a Trade such as prior experience,
                                       make sure those criteria are met and described by the projects
                                       listed. (Note: See Legal if you wish to add or change definition of
                                       Similar Project and delete this note prior to finalizing document)
                                         28 points available

                             c.        Terminations: Provide a list of any projects on which the firm
                                       was terminated, held in default, or failed to complete the work
                                       within the last five (5) years. Include the name of the project, the
                                       timeframe of the project and circumstances surrounding the
                                       termination or default. Joint ventures must a list of termination for
                                       each joint venture partner.     5 points available




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                10
                             d.        Lawsuits: Provide a list of all lawsuits in which the trade
                                       contractor is a defendant or defendant-in-counterclaim with regard
                                       to construction contracts within the last 3 years. Please include
                                       among the lawsuits requested in the previous sentence, payment
                                       bond lawsuits under G.Lc.149, §29 and mechanics lien lawsuits. If
                                       the lawsuit was pending at any time during the last three (3) years
                                       (which includes any lawsuit that was commenced, dismissed, or
                                       resolved by settlement or judgment during that time), then it must
                                       be listed. Please note that the lawsuits listed shall not include
                                       actions that primarily involve personal injury, workers’
                                       compensation claims, or where the sole cause of action involves
                                       the trade contractor’s exercise of its rights for direct payment under
                                       MLG c 30, §39F. Joint ventures must provide information
                                       regarding lawsuits for each joint venture partner. 3 points
                                       available

                             e.        Safety Record: Provide the three (3) year history of the Trade
                                       Contractor’s workers’ compensation experience modifier. In
                                       addition, provide documentation from the Trade Contractor’s
                                       insurance carrier supporting the rating history provided. Joint
                                       ventures must provide the safety history for each joint venture
                                       partner. 5 points available

                   2.        References - (30 points available in this category; minimum of 15 points
                             required in this category for prequalification approval)

                             a.        Project References: Provide reference information for owners and
                                       architects for each and every project listed in the response to
                                       Section VI(C)(1)(c), “Similar Project Experience.” Joint ventures
                                       must provide project references for each joint venture partner.
                                       Information provided shall at least include project name and the
                                       names of the owners and architects, with current address, current
                                       telephone and fax numbers, and a contact person for each.
                                       Note: The Prequalification Committee may also consider project
                                       reference information and project evaluations obtained from the
                                       Update Statement, DCAM’s certification files and information
                                       provided in response to Subsection 2(c) herein. 24 points
                                       available

                             b.        Credit References: Provide a minimum of five (5) credit reference-
                                       s, including the telephone and fax numbers of a contact person from
                                       key suppliers, vendors and banks. Joint ventures must provide credit
                                       references for each joint venture partner. 1 points available

                             c.        Public Project Record: Provide a list of all completed public
                                       building construction projects (as defined by M.G.L. c. 149 §44A
DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                11
                                       worked on during the past three (3) years with the project name,
                                       scope of work, contract value, start date, completion date, status of
                                       the project, owner’s name (including address, telephone number,
                                       fax number, and contact person) and architect’s name (including
                                       address, telephone number, fax number and contact person). Joint
                                       ventures must provide public project record information for each
                                       joint venture partner. 5 points available

                   3.        Capacity to Complete Projects - (20 points available in this category;
                             minimum of 10 points required in this category for prequalification
                             approval)

                             a.        Prior Revenue: Submit the prior annual revenue for the prior
                                       three (3) fiscal years. Joint ventures must provide prior annual
                                       revenue for each joint venture partner. 10 points
                             b.        Revenue Under Contract: Submit revenue under contract for the
                                       next three (3) years. Joint ventures must provide revenue under
                                       contract for each joint venture partner. 10 points

                   4.        Mandatory Requirements - (no points assigned)

                             a.        Bonding Capacity: Interested Trade Contractors must provide a
                                       commitment letter (from a surety company licensed to do business
                                       in the Commonwealth of Massachusetts and whose name appears
                                       on the United States Treasury Department Circular 570) for
                                       payment and performance bonds in an amount equal to or greater
                                       than one hundred and ten percent (110%) of the estimated trade
                                       contract value for the subtrade that the Trade Contractor is seeking
                                       prequalification as set forth in Section I.

                             b.        DCAM Certification: Respondent Trade Contractors must be
                                       certified as a filed sub-bidder in the trade for which they seek
                                       to be prequalified by DCAM and pursuant to M.G.L. c. 149,
                                       §44D must submit a copy of the Respondent’s currently valid
                                       DCAM Sub-bidder Certificate of Eligibility with its SOQ (as set
                                       forth in the General Information section above). Note, however,
                                       that a joint venture team must be certified in specific trade(s) that it
                                       is seeking to be prequalified for this Project in the name of the joint
                                       venture and must submit a Sub-bidder Certificate of Eligibility for
                                       the joint venture in each such Trade. If a respondent to the RFQ is
                                       a proposed joint venture that is newly formed or is not currently
                                       certified, then: (i) each party to the proposed joint venture must be
                                       individually certified by DCAM and must submit a copy of its
                                       DCAM Sub-bidder Certificate of Eligibility with the JV SOQ; and
                                       (ii) the joint venture respondent must state in the SOQ that it will
                                       seek certification from DCAM as a joint venture in the sub-bid
                                       category of the Trade for which they submit the RFQ, and state that
DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                12
                                       it understands and agrees that if the joint venture respondent is
                                       selected to participate in the RFB phase it will be required to
                                       submit a DCAM Sub-bidder Certificate of Eligibility for the joint
                                       venture in the name of the joint venture with its response to the
                                       RFB. For certification forms and additional information see our
                                       web site:
                                       www.mass.gov/dcam/certification

                                       Or contact the Certification Office at:

                                                 DCAM Contractor Certification Office
                                                 One Ashburton Place,
                                                 Boston, Massachusetts 02108
                                                 Telephone Number (617) 727-4050 ext. 415

                             c.        Update Statement: Interested Trade Contractors must provide a
                                       current and completed Sub-bidder Update Statement prepared by
                                       the interested Trade Contractor utilizing the current form of Update
                                       Statement available on the DCAM website. If a respondent to the
                                       RFQ is a proposed joint venture and the proposed joint venture is
                                       not yet certified, then: i) each party to the proposed joint venture
                                       must be certified by DCAM and each must submit its own signed
                                       Sub-bidder Update Statement as part of its SOQ; ii) at least one of
                                       the parties to the joint venture must be certified by DCAM in the
                                       Trade category of for which it is seeking prequalification. When
                                       the second phase of the selection process is undertaken through an
                                       RFB, a joint venture respondent that has been selected in the RFQ
                                       process will be required to submit its Sub-bidder Certificate of
                                       Eligibility for the joint venture meeting the above requirements
                                       with its proposal to the RFB.

                                       For the required Sub-bidder Update Statement Form and additional
                                       information see our web site:
                                       www.mass.gov/dcam/certification

                                       Or contact the Certification Office at:

                                                 DCAM Contractor Certification Office
                                                 One Ashburton Place,
                                                 Boston, Massachusetts 02108
                                                 Telephone Number (617) 727-4050 ext. 415




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                13
Section VII: Additional Information

         A.        Status of Request For Qualifications

                   This RFQ is solely a request for information. It does not represent an offer nor
                   does it confer any rights on any respondent Trade Contractor. DCAM shall not be
                   responsible under any circumstances for any costs incurred by any respondent
                   Trade Contractors in responding to this RFQ. DCAM reserves the right to cancel
                   this procurement at any time if it is in its best interest to do so.

         B.        Treatment of Information Submitted

                   With the exception of the required Update Statement and financial information,
                   DCAM shall have no obligation to treat any information submitted by an
                   interested Trade Contractor in or in connection with a SOQ as proprietary or
                   confidential unless DCAM determines that the information legitimately requires
                   such treatment. In such case, DCAM’s obligation with respect to protection and
                   disclosure of such information shall at all times be subject to applicable laws.
                   DCAM shall have the right to use all or portions of the SOQ, as it considers
                   necessary or desirable in connection with the Project. By the submission of a
                   SOQ, the respondent Trade Contractor thereby grants to DCAM an unrestricted
                   license to use the SOQ, including all materials submitted therewith, in connection
                   with the project.

         C.        Communication between DCAM and Respondent Trade Contractors

                   Unauthorized communications or contact between Trade Contractors, their
                   employees, agents or other related entities interested in submitting a SOQ and
                   DCAM, the project designer, the project manager, the construction manager at
                   risk firm or any other person or entity participating on the Prequalification
                   Committee with regard to the Project are strictly prohibited. The only authorized
                   communications shall be 1) inquiries to DCAM for general information about
                   obtaining the RFQ, RFQ submission deadlines, and the existence of any relevant
                   addenda to the RFQ; and 2) inquiries made at any official RFQ Informational
                   meeting and/or site visit held by DCAM. If applicable, the official RFQ
                   Informational meeting will be held at the date(s) and time(s) set forth in Section I.

                   Any issues brought to DCAM’s attention at the Pre-RFQ Informational meeting,
                   which DCAM determines will require additional clarification will be addressed by
                   issuing a written addendum. Oral and other clarifications will be without legal
                   effect. All such addenda will be considered part of this RFQ, and the respondent
                   Trade Contractor shall be required to acknowledge receipt of all addenda on the
                   RFQ Proposal Response Form attached to this RFQ. DCAM will mail addenda to
                   all respondent Trade Contractors that have mailed or faxed an RFQ Interest Form,
                   Trade RFQ Form 1 to DCAM or have received the RFQ directly from DCAM. It
DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                14
                   shall be the sole responsibility of the respondent Trade Contractor to ascertain the
                   existence of any and all addenda issued by DCAM.

                   From the date of issuance of this RFQ, any respondent Trade Contractor that
                   contacts directly or indirectly any member or employee of DCAM, or the project
                   designer, or the project manager, or the construction manager at risk firm, or any
                   member of the Prequalification Committee in connection with the selection
                   process or the contract contemplated herein for this project is subject to
                   disqualification. Contact is permitted for the purpose of obtaining a copy of this
                   RFQ or to submit a verbal or written question or request for clarification at the
                   RFQ Informational meeting as set forth in Section I.




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                15
          Part Two: Trade Contractor SOQ Application Forms/Schedules
                                    (To be completed by Trade Contractor)
                                 TRADE CONTRACTOR RFQ Interest Form
                                           (TRADE RFQ Form 1)
                                  (For Submission to DCAM Immediately)
Instructions: If respondent Trade Contractor firm is interested in responding to the RFQ for Prequalification of
Trade Contractors for this Project then Trade RFQ Form 1 MUST be submitted to DCAM BEFORE submitting
the SOQ Application Trade RFQ Form 3.

       Awarding Authority:                                      Division of Capital Asset Management
       Project No.:                                             (Insert Project No.)
       Project Name:                                            (Insert Project Name)

         Mail or Fax this RFQ Interest Form to1:
                             DCAM Bid Room, Room 1610
                             Division of Capital Asset Management
                             One Ashburton Place, 16th Floor
                             Boston, MA 02108
                             Facsimile number (617) 727-5514
By submitting this Trade RFQ Interest Form the below identified firm is expressing its interest in the above-
referenced public building construction project and is requesting that it be added to the list of firms that will receive
any addenda to the RFQ on the Project. DCAM assumes no responsibility for a firm’s failure to receive any
addenda or other correspondence related to this RFQ due to the firm’s failure to submit an RFQ Interest Form
as directed above or for any other reason.

      Trade Contractor Category:

      Trade Contractor Firm Name:

      Trade Contractor Address:

      Trade Contractor Telephone:

      Trade Contractor Facsimile:

      Trade Contractor E-mail

      Trade Contractor Contact
      Person/Title:
      Date Submitted:

By:                _______________________________________                             Date: _________________
                   (Signature of Authorized Representative)

1
  Note: The Statement of Qualifications (“SOQ”) application form (TRADE RFQ Form 3) and accompanying
Schedules A through M, submitted in response to this RFQ MAY NOT BE FAXED.

DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number
      TRADE CONTRACTOR RFQ RESPONSE CHECKLIST - TRADE RFQ Form 2
PLEASE NOTE THAT INCOMPLETE OR LATE APPLICATIONS FOR PREQUALIFICATION WILL
NOT BE CONSIDERED. THEREFORE, BEFORE SUBMITTING A RESPONSE TO THIS RFQ, PLEASE
REVIEW THE FOLLOWING:
                   Did respondent Trade Contractor fax or mail the RFQ Interest Form (Trade RFQ
                   Form 1) to DCAM?
                   Did respondent Trade Contractor complete the entire SOQ application (Trade
                   RFQ Form 3) and all required attachments and schedules?
                   Did respondent Trade Contractor fully complete Schedules A through M and
                   attach all required documentation?
                   Did respondent Trade Contractor attach the resumes of owners and management
                   personnel identified in respondent Trade Contractor’s responses to Schedule A and
                   Schedule B?
                   Did respondent Trade Contractor attach the required documentation from
                   respondent Trade Contractor’s insurance company supporting the workers’
                   compensation modifier history reported in Schedule F?
                   Does respondent Trade Contractor have the current contact information for all of
                   the references reported in Schedule G, Schedule H and Schedule I?
                   Did respondent Trade Contractor attach a commitment letter for payment and
                   performance bonds in the form required and for a value of 110% of the trade
                   contract value as required in Section 4(a) of Part Two, Trade RFQ Form 3?
                   Did respondent Trade Contractor attach a currently valid DCAM Sub-bidder
                   Certificate of Eligibility as required in Section 4(b) of Part Two, Trade RFQ Form
                   3?
                   Did respondent Trade Contractor attach a completed and signed Sub-bidder
                   Update Statement using the most recent form available on the DCAM website as
                   required in Section 4(c) of Part Two, Trade RFQ Form 3?
                   Did respondent Trade Contractor include the original and all required copies of
                   respondent Trade Contractor’s entire SOQ application package?
                   Did respondent Trade Contractor address the SOQ envelope correctly (i.e. to
                   reference the Project and other required information set forth herein)?
                   Did respondent Trade Contractor review all of the execution requirements before
                   signing the SOQ application form?
                   Is the person who signed the SOQ application form authorized to do so and did
                   his or her correct and current contact information?




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                2
          DIVISION OF CAPITAL ASSET MANAGEMENT
   TRADE CONTRACTOR STATEMENT OF QUALIFICATIONS FORM
                    (TRADE RFQ FORM 3)




Massachusetts State Project (Insert Project Number)

(Insert Full Project Name, City/Town, Massachusetts)
Note: See Sections III and VII of Part One of the RFQ, for instructions on completing this
      Statement of Qualifications and accompanying Schedules A through M.

Trade Contractor Category

Trade Contractor Name:

Trade Contractor Mailing Address:

Trade Contractor Street Address:

Telephone Number:

Trade Contractor E-mail

Facsimile Number:

Contact Person/Title:

Trade Contractor Acknowledges
Addenda Nos.

Note: If Respondent Trade Contractor is “SOMWBA Certified” as a MBE/WBE/MWBE,
      please indicate which below and attach letter from the State Office of Minority and
      Women Business Assistance evidencing such certification.

                                    MBE                 WBE         M/WBE

DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                1
           ******************** IMPORTANT NOTICE **********************

           Interested TRADE CONTRACTORS must indicate in the table below the
           trade for which it is seeking prequalification in this SOQ submission and
             MUST submit SEPARATE individual SOQ forms for each and every
               other trade that it is also seeking prequalification for this Project.

           ******************** IMPORTANT NOTICE **********************


     Mark “X” for                 Section #           Trade Category
     Trade Seeking
     Prequalification
                                  040001              Masonry
                                  050001              Miscellaneous and Ornamental Iron
                                  070001              Waterproofing, Dampproofing and Caulking
                                  070002              Roofing and Flashing
                                  080001              Metal Windows
                                  080002              Glass and Glazing
                                  090001              Lathing and Plastering
                                  090002              Tile
                                  090003              Acoustical Tile
                                  090004              Marble
                                  090005               Resilient Floors
                                  090006              Terrazzo
                                  090007              Painting
                                  140001              Elevators
                                  210001              Fire Protection Sprinkler System
                                  220001              Plumbing
                                  230001              Heating, Ventilation & Air-Conditioning
                                  260001              Electrical
                                  (Sec. #)            Other Designated Trade Categories (if any)




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                2
1.       Management Experience - (50 points available; minimum of 25 points required for
         prequalification approval)

         a.        Business Owners: Interested Trade Contractors MUST COMPLETE Schedule
                   A and MUST ATTACH to it a resume for each and every business owner of
                   respondent Trade Contractor firm as set forth in Section VI(C)(1)(a) of Part One,
                   the RFQ for this Project.

         b.        Management Personnel: Interested Trade Contractors MUST COMPLETE
                   Schedule B and MUST ATTACH to it an organizational chart AND a resume for
                   each and every person who will have any management responsibility, direct or
                   indirect, for the Project, including, but not limited to, project executives, project
                   managers, field superintendents and field engineers, as set forth in Section
                   VI(C)(1)(b) of Part One, the RFQ for this Project.

           c.      Similar Project Experience: Interested Trade Contractors MUST COMPLETE
                   Schedule C and list similar projects for the last five (5) years. For each project,
                   respondent Trade Contractor must include the name, location, owner, description
                   of project, a detailed description of respondent Trade Contractor’s scope of work,
                   original contract sum and final contract sum, with explanation, for this scope of
                   work only and date completed. For the purpose of this RFQ, “similar projects”
                   shall be defined as defined in Section VI(C)(1)(c) of Part One, the RFQ for this
                   Project. If specific criteria are required for a Trade, such as prior experience,
                   make sure those criteria are met and described by the projects listed.

         c.        Terminations: Interested Trade Contractors MUST COMPLETE Schedule D
                   and list each and every project on which respondent Trade Contractor was
                   terminated or failed to complete the work within the last five (5) years as set forth
                   in Section VI(C)(1)(d) of Part One, the RFQ for this Project.

         d.        Lawsuits: Interested Trade Contractors MUST COMPLETE Schedule E and
                   list of all lawsuits in which the trade contractor is a defendant or defendant-in-
                   counterclaim with regard to construction contracts within the last 3 years. Please
                   include among the lawsuits requested in the previous sentence, payment bond
                   lawsuits under G.Lc.149, §29 and mechanics lien lawsuits. If the lawsuit was
                   pending at any time during the last three (3) years (which includes any lawsuit that
                   was commenced, dismissed, or resolved by settlement or judgment during that
                   time), then it must be listed. Please note that the lawsuits listed shall not include
                   actions that primarily involve personal injury, workers’ compensation claims, or
                   where the sole cause of action involves the trade contractor’s exercise of its rights
                   for direct payment under MLG c 30, §39F. Joint ventures must provide
                   information regarding lawsuits for each joint venture partner as set forth in
                   Section VI(C)(1)(e) of Part One, the RFQ for this Project.




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                3
         e.        Safety Record: Interested Trade Contractors MUST COMPLETE Schedule F
                   and provide the three (3) year history of its workers’ compensation modifier rating
                   as set forth in Section VI(C)(1(f) of Part One, the RFQ for this Project, and
                   MUST ATTACH to Schedule F documentation from its insurance carrier
                   supporting the ratings reported therein or no points may be awarded.

2.       References - (30 points available; minimum of 15 points required for prequalification
         approval)

         a.        Project References: Interested Trade Contractors MUST COMPLETE
                   Schedule G and provide project references from owners and architects for all
                   projects listed in Schedule C as required in Section VI(C)(2)(a) of Part One, the
                   RFQ for this Project.

         b.        Credit References: Interested Trade Contractors MUST COMPLETE Schedule
                   H and provide a minimum of five (5) credit references as required in Section
                   VI(C)(2)(b) of Part One, the RFQ for this Project.

         c.        Public Project Record: Interested Trade Contractors MUST COMPLETE
                   Schedule I and list all completed public building construction projects completed
                   by respondent Trade Contractor during the past three (3) years as required in
                   Section VI(C)(2)(c) of Part One, the RFQ for this Project.

3.       Capacity to Complete Project - (20 points available; minimum of 10 points are required
         for prequalification approval)

         a.        Prior Revenue: Interested Trade Contractors MUST COMPLETE Schedule
                   J and list prior revenue for the last three (3) fiscal years.

         b.        Revenue Under Contract: Interested Trade Contractors MUST COMPLETE
                   Schedule K and list revenue under contract for the next three (3) fiscal years.

4.       Mandatory Requirements: (no points are assigned)

         a.        Payment and Performance Bonds: Interested Trade Contractors MUST
                   ATTACH to the Trade RFQ Form 3 at Schedule L a commitment letter (from a
                   surety company licensed to do business in the Commonwealth of Massachusetts
                   and whose name appears on United States Treasury Department Circular 570) for
                   payment and performance bonds in an amount equal to or greater than one
                   hundred ten percent (110%) of the estimated trade contract value of this Project.

         b.        Sub-bidder Certificate of Eligibility: (Required as of January 1, 2006)
                   Interested Trade Contractors MUST ATTACH to the Trade RFQ Form 3 at
                   Schedule M a currently valid Sub-bidder Certificate of Eligibility (issued by
                   DCAM) for each Trade in which it submits a SOQ.

DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                4
         c.        Update Statement: (Required as of January 1, 2006) Interested Trade
                   Contractors MUST ATTACH to the Trade RFQ Form 3 at Schedule M a current
                   and completed Sub-bidder Update Statement for each Trade in which it submits
                   and RFQ utilizing the current Update Statement form available on DCAM’s
                   website.

5.       Execution Requirements

         a.        Submission Format: Submit the original, marked “Original” clipped, not stapled,
                   together and five (5) complete copies of the interested Trade Contractor’s SOQ.
                   Copies should be stapled together and submitted without any binders, dividers or
                   report covers.

         b.        RFQ Response Checklist: Before signing and submitting its SOQ application
                   package for this Project, interested Trade Contractors are advised to carefully
                   review the RFQ Response Checklist – Trade RFQ Form 3.

         c.        Incomplete or Inaccurate Information: Failure to accurately and completely
                   provide the information requested may result in disqualification.

         d.        Authorization to Sign: This form MUST be signed by an officer of the firm or
                   an individual so authorized by an officer of the firm who has personal knowledge
                   regarding the information contained herein.

         e.        Debarment Status: By signing below, the interested Trade Contractor certifies
                   that it is not currently debarred from performing public work for the
                   Commonwealth of Massachusetts or the Federal Government.




                                [THIS SPACE IS INTENTIONALLY BLANK]




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                5
                                                       Certification
          The undersigned declares that he or she has carefully examined all the documents contained in
the CM at Risk Request for Qualifications (RFQ) solicitation for the project, and certifies to the best of
his/her knowledge, that this Statement of Qualifications fully complies with all of the requirements of the
RFQ and all addenda and clarifications issued in regard to the RFQ.
          The undersigned also hereby certifies that he or she (or, if he or she is the authorized
representative of a company, the company) is the only person interested in this Statement of
Qualifications and any subsequent proposal; that it is made without any connection with any other person
making any submission for the same work; that no person acting for, or employed by, the Commonwealth
of Massachusetts is directly or indirectly interested in this Statement of Qualifications or any subsequent
proposal, or in any contract which may be made under it, or in expected profits to arise therefrom; that
the undersigned Respondent has not influenced or attempted to influence any other person or corporation
to file a Statement of Qualifications or subsequent proposal or to refrain from doing so or to influence the
terms of the Statement of Qualifications or any subsequent proposal of any other person or corporation;
and that this submission is made in good faith without collusion or connection with any other person
applying for the same work.
          The undersigned further certifies under pains and penalties of perjury that the undersigned is not
debarred from doing public construction work in the Commonwealth of Massachusetts under the
provisions of section twenty nine F of chapter twenty nine, or any other applicable debarment provision
of any other chapter of the General Laws or any rule or regulation promulgated there under, and further is
not debarred from doing public construction work under any law, rule or regulation of the federal
government.
          The undersigned states that he or she has carefully examined all of the information provided and
representations made in this Statement of Qualifications and the documents submitted with the SOQ
including all schedules, forms and materials, and certifies to the best of his/her knowledge, that this
Statement of Qualifications in its entirety is complete, true and accurate.
Acknowledgement of Addenda. By signing below, the interested Trade Contractor acknowledges
receipt of the following addenda to this RFQ:

                                       Addenda No. (if any) __________________

SIGNED UNDER THE PAINS AND PENALTIES OF PERJURY:

         Signature:
                                       (Signature of Authorized Representative)
         Print Name:

         Title:

         Firm Name:

         Date:

         Project Number:               _                   ____________________________________

         Project Name:




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                6
                                                                                                 Firm Name:

SCHEDULE A – BUSINESS OWNERS: Interested Trade Contractor MUST provide the following information and attach a copy of the
resume for each and every business owner of the firm in accordance with Section VI(C)(1)(a) of Part One, the RFQ for this Project.

                                                   ROLE/JOB RESPONSIBILITIES/       # OF YEARS
        NAME                   TITLE                    SCOPE OF WORK                 W/FIRM             EDUCATION/EXPERIENCE




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                                7
                                                                                                         Firm Name:

SCHEDULE B – MANAGEMENT PERSONNEL: Interested Trade Contractors MUST provide the following information
and attach (1) an organizational chart and (2) copies of the resumes for each and every person who will have any direct or indirect
management responsibility for the Project, including but not limited to, project executives, project managers, project superintendents,
etc. in accordance with Section VI(C)(1)(b) of Part One, the RFQ for this Project.

                                                                           # OF
                                             ROLE/JOB RESPONSIBILITIES/   YEARS
        NAME                  TITLE               SCOPE OF WORK           W/FIRM        EDUCATION/EXPERIENCE                COMPLETED PROJECTS




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                            8
                                                                                                          Firm Name:

SCHEDULE C - SIMILAR PROJECT EXPERIENCE: Interested Trade Contractor MUST list all similar projects respondent Trade
Contractor has completed during the last five (5) years. For the purpose of this RFQ “similar projects” shall be as defined in Section VI(C)(1)(c) of
the RFQ which requests projects of similar dollar value, size, scope and complexity as this Project. For each project listed provide a detailed
description of the scope of work performed and provide contract amounts for that scope of work only.
If specific criteria are required for a Trade such as prior experience, make sure those criteria are met and described by the projects listed.

                                                                                                                                  START AND
     PROJECT NAME &                       PROJECT               PROJECT DESCRIPTION AND        ORIGINAL AND FINAL                COMPLETION
        LOCATION                           OWNER                DETAILED DESCRIPTION OF       CONTRACT AMOUNT AND                   DATES
                                                                     SPECIFIC SCOPE               EXPLANATION               (M/D/YYYY – M/D/YYYY)




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                               9
                                                                                                        Firm Name:

SCHEDULE D - TERMINATIONS: Interested Trade Contractors are required to list each and every project on which it was
terminated or failed to complete the project as set forth in Section VI(C)(1)(d) of Part One, the RFQ for this Project within in the prior
five (5) years.

                                                                                                                             %             REASON FOR
                                                                                                                          COMPLETE       TERMINATION OR
 PROJECT NAME &                     SCOPE OF WORK               CONTRACTED   START & END           ESTIMATED                               FAILURE TO
    LOCATION                          PERFORMED                    WITH         DATES           CONTRACT AMOUNT                             COMPLETE




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                             10
                                                                                                          Firm Name:

         SCHEDULE E - LAWSUITS: Interested Trade Contractors are required to list of all lawsuits in which the trade contractor is a defendant
         or defendant-in-counterclaim with regard to construction contracts within the last 3 years. Please include among the lawsuits requested in the
         previous sentence, payment bond lawsuits under G.Lc.149, §29 and mechanics lien lawsuits. If the lawsuit was pending at any time during the
         last three (3) years (which includes any lawsuit that was commenced, dismissed, or resolved by settlement or judgment during that time), then
         it must be listed. Please note that the lawsuits listed shall not include actions that primarily involve personal injury, workers’ compensation
         claims, or where the sole cause of action involves the trade contractor’s exercise of its rights for direct payment under MLG c 30, §39F. Joint
         ventures must provide information regarding lawsuits for each joint venture partner as set forth in Section VI(C)(1)(e) of Part One, the RFQ
         for this Project.
PROJECT NAME & LOCATION                       PROJECT OWNER      DESCRIPTION OF LEGAL PROCEEDING (include caption of case, parties, location of
                                                                 proceeding, description of the dispute and status and/or outcome)




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                           11
                                                                                    Firm Name:

SCHEDULE F – SAFETY RECORD: Interested Trade Contractors are required to provide the three (3) three year history of its
workers’ compensation experience modifier and attach documentation from its insurance carrier supporting the ratings reported
herein as set forth in Section VI(C)(1)(f) of Part One, the RFQ for this Project.

                           YEAR                        WORKERS’ COMP. EXPERIENCE    COMMENTS
                                                       MODIFIER




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                               12
                                                                                                        Firm Name:

SCHEDULE G - PROJECT REFERENCES: Interested Trade Contractors are required to list references for prior work respondent Trade
Contractor has performed which appears in Schedule C as set forth in Section VI(C)(2)(a) of Part One, the RFQ for this Project.




             PROJECT TITLE                                      COMPANY NAME   CONTACT PERSON/ADDRESS          TELEPHONE#         FAX#
                                             OWNER:
                                             DESIGNER:


                                             OWNER:
                                             DESIGNER:


                                             OWNER:
                                             DESIGNER:


                                             OWNER:
                                             DESIGNER:


                                             OWNER:
                                             DESIGNER:




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                               13
                                                                                           Firm Name:

SCHEDULE H - CREDIT REFERENCES: Interested Trade Contractors are required to list a minimum of five (5) credit references from
banks, suppliers and/or vendors as set forth in Section VI(C)(2)(b) of Part One, the RFQ for this Project.

           CHECK ONE                             COMPANY NAME   CONTACT PERSON             TELE#        FAX#

               BANK
               SUPPLIER
               VENDOR



               BANK
               SUPPLIER
               VENDOR


               BANK
               SUPPLIER
               VENDOR


               BANK
               SUPPLIER
               VENDOR


               BANK
               SUPPLIER
               VENDOR




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                  14
                                                                                                         Firm Name:

SCHEDULE I - PUBLIC PROJECT RECORD: – Interested Trade Contractors are required to list all completed public buildings during the
past three (3) years in accordance with Section VI(C)(2)(c) of Part One, the RFQ for this Project. (Respondent Trade Contractor may attach
additional pages if necessary).

                                      PROJECT INFORMATION                                         CONTACT INFORMATION
                                                                                  Provide business and contact name, address, telephone and fax
        PROJECT NAME:
                                                                               AWARDING AUTHORITY:
        CONTRACT VALUE:

        SCOPE:                                                                 DESIGNER:

        START DATE:
        FINISH DATE:

        PROJECT NAME:                                                          AWARDING AUTHORITY:

        CONTRACT VALUE:
                                                                               DESIGNER:
        SCOPE:

        START DATE:
        FINISH DATE:

        PROJECT NAME:                                                          AWARDING AUTHORITY:

        CONTRACT VALUE:
                                                                               DESIGNER:
        SCOPE:

        START DATE:
        FINISH DATE:




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                         15
                                                                                                Firm Name:

SCHEDULE J – PRIOR REVENUE: – Interested Trade Contractors are required to list prior revenue for the last three (3) fiscal years in
accordance with Section VI(C)(3)(a) of Part One, the RFQ for this Project.

Firm’s fiscal year runs                to          .

                                                          YEAR   PRIOR ANNUAL REVENUE ($)




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                            16
                                                                                                       Firm Name:

SCHEDULE K – REVENUE UNDER CONTRACT: – Interested Trade Contractors are required to list revenue under contract for next
three (3) fiscal years in accordance with Section VI(C)(3)(b) of Part One, the RFQ for this Project.

Firm’s fiscal year runs                to          .

                                                          YEAR   REVENUE UNDER CONTRACT ($)




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                            17
                                                                                       Firm Name:


Schedule L – LETTER EVIDENCING BONDING CAPACITY


Respondent Trade Contractors must attach here a letter from a surety company (or from an agent meeting the criteria set
forth above) evidencing that the surety will provide respondent with payment and performance bonds for the Project in an
amount equal to or greater than One Hundred and Ten Percent (110%) of the estimated trade contract value of the Project. The
surety company must meet the requirements set forth above. For Trade Contractors submitting SOQs for more than one Trade,
a letter evidencing bonding capacity for each trade must be submitted.




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                18
                                                                                            Firm Name:


Schedule M – SUB-BIDDER CERTIFICATE OF ELIGIBILITY AND SUB-BIDDER UPDATE STATEMENT


Respondent Trade Contractors must attach here TWO different documents:

              1) a copy of its current DCAM Sub-Bidder Certificate of Eligibility meeting the requirements set forth above in this
                 RFQ; and

              2) a completed and signed DCAM Sub-bidder Update Statement utilizing the most current form available on
                 DCAM’s website. www.mass.gov/dcam/certification


Note: Trade Contractors submitting an SOQ for more than one Trade must submit a DCAM Sub-bidder Certificate of
Eligibility and Sub-bidder Update Statement for each Trade.




DCAM CM at Risk Standard Trade Contractor RFQ (8/12 template)
Insert Project Name and Project Number

                                                                  19

				
DOCUMENT INFO
Shared By:
Categories:
Tags:
Stats:
views:2
posted:11/4/2012
language:Latin
pages:37